Effective Date: September 6, 2026
Last Updated: September 6, 2026

Welcome to the E Windowtastic website. These Terms of Use govern your access to and use of https://www.ewindowtastic.com/ and any related pages, content, features, and services made available through the website.

The website is operated by Egress Windowtastic, doing business as E Windowtastic (“E Windowtastic,” “we,” “us,” or “our”).

By accessing or using this website, you agree to these Terms of Use. If you do not agree, please do not use the website.

1. Website Purpose

E Windowtastic provides information about European-engineered windows, doors, related products, consultation services, delivery options, and completed or ongoing projects.

The website is intended for general informational and business-inquiry purposes. Website content does not constitute a binding offer, construction advice, engineering advice, architectural advice, or a guarantee that a particular product is appropriate for your project.

2. Eligibility

You must be at least 18 years old and legally capable of entering into an agreement to use this website for purchases, quotations, or other business transactions.

If you use the website on behalf of a company or organization, you represent that you have authority to act on its behalf.

3. Acceptable Use

You agree to use the website only for lawful purposes. You may not:

• Violate any applicable law or regulation
• Submit false, misleading, fraudulent, or unauthorized information
• Attempt to gain unauthorized access to the website, server, or connected systems
• Introduce malware, viruses, harmful code, or disruptive technology
• Interfere with the website’s performance, security, or availability
• Scrape, harvest, copy, or extract website data through automated means without written permission
• Impersonate another person or organization
• Use website content to misrepresent an affiliation with E Windowtastic
• Reproduce or commercially exploit website content without authorization
• Use the website in a way that could harm E Windowtastic, its customers, suppliers, or partners

We may restrict or terminate access to the website if we reasonably believe these Terms have been violated.

4. Product Information

We make reasonable efforts to present accurate information about our products, including materials, dimensions, colors, finishes, configurations, energy-performance values, certifications, features, and availability.

However:

• Images and renderings are provided for illustration
• Colors and finishes may appear differently depending on the screen or lighting
• Measurements, specifications, and product features may change
• Product availability may depend on manufacturers, suppliers, and shipping conditions
• Performance may vary based on product configuration, installation, building design, climate, elevation, maintenance, and other project conditions
• Typographical or technical errors may occasionally occur

You should confirm all specifications, dimensions, certifications, performance requirements, and project details in writing before placing an order.

We reserve the right to correct errors and update website information without prior notice.

5. Quotes and Estimates

Requests submitted through the website do not create a binding agreement.

Any preliminary price, estimate, timeline, or recommendation communicated through the website, email, or an initial conversation is subject to review and may change based on:

• Final dimensions and quantities
• Product configuration
• Glass, hardware, finish, and accessory selections
• Project location and site conditions
• Manufacturing and material costs
• Freight, delivery, storage, duties, and taxes
• Installation requirements
• Engineering or code requirements
• Supplier availability
• Changes requested by the customer

A quote becomes binding only when confirmed through a separate written agreement, order confirmation, proposal, invoice, or contract accepted by the parties.

Unless stated otherwise in writing, quotes are valid only for the period shown on the applicable quotation.

6. Measurements and Project Information

You are responsible for providing accurate and complete measurements, drawings, specifications, delivery details, and other project information.

E Windowtastic is not responsible for costs, delays, fit issues, or other problems resulting from inaccurate or incomplete information supplied by the customer or a third party.

Final measurements and project requirements should be confirmed by a qualified contractor, architect, engineer, installer, or other appropriate professional when necessary.

7. Orders, Payments, Delivery, and Installation

Product orders, deposits, payments, manufacturing, cancellations, returns, warranties, delivery, storage, installation, and related services may be governed by a separate proposal, invoice, purchase agreement, installation agreement, warranty, or manufacturer’s terms.

If there is a conflict between these Terms of Use and a signed or accepted project-specific agreement, the project-specific agreement will control for that transaction.

Manufacturing and delivery dates are estimates unless expressly guaranteed in writing. Delays may occur because of production schedules, customs, freight carriers, weather, material availability, labor interruptions, governmental action, or other circumstances outside our reasonable control.

Customers are responsible for ensuring that delivery locations are accessible and ready to receive products unless otherwise agreed in writing.

8. Building Codes and Professional Advice

Building codes, permit requirements, energy-efficiency standards, egress requirements, safety-glazing rules, structural requirements, and other regulations vary by location and project.

Customers, property owners, contractors, architects, engineers, and installers are responsible for confirming that selected products and installations comply with all applicable laws, codes, permits, plans, and project requirements.

Information on this website is not a substitute for advice from a licensed architect, engineer, contractor, building official, or other qualified professional.

9. Intellectual Property

Unless otherwise stated, the website and its content—including text, graphics, photographs, videos, layouts, logos, icons, designs, downloads, and other materials—are owned by or licensed to E Windowtastic and are protected by intellectual-property laws.

You may view and print website content for your personal, noncommercial evaluation of E Windowtastic’s products and services.

You may not reproduce, republish, distribute, modify, display, sell, license, create derivative works from, or commercially exploit website content without prior written permission from E Windowtastic or the applicable rights holder.

Product names, trademarks, photographs, and materials belonging to manufacturers or other third parties remain the property of their respective owners.

10. Project Photographs and Examples

Photographs, renderings, descriptions, testimonials, and project examples are provided to demonstrate past work, available products, or possible applications.

Every project is different. Previous results do not guarantee identical appearance, performance, pricing, timing, or outcomes for another project.

Project locations or names may be generalized or abbreviated to protect customer privacy.

11. Downloads and Installation Guides

The website may provide installation guides, checklists, brochures, specifications, or other downloadable materials.

These materials are provided for general informational purposes and may not address every project condition or local requirement. Installation should be completed or supervised by appropriately qualified professionals.

Users are responsible for confirming that they are using the latest applicable document version and following manufacturer instructions, approved plans, building codes, and project-specific requirements.

E Windowtastic is not responsible for damage, injury, product failure, code violations, or additional costs caused by improper handling, storage, installation, modification, maintenance, or use.

12. Third-Party Websites and Services

The website may contain links to manufacturers, suppliers, certification organizations, social-media platforms, maps, videos, or other third-party websites and services.

These links are provided for convenience. E Windowtastic does not control and is not responsible for third-party content, availability, security, products, services, or privacy practices.

A link does not necessarily mean that E Windowtastic endorses or guarantees the third party. Your use of third-party services is subject to their own terms and policies.

13. Privacy

Your use of the website is also governed by our Privacy Policy. The Privacy Policy explains how we collect, use, disclose, and protect personal information.

14. Disclaimer of Warranties

To the fullest extent permitted by law, the website and its content are provided on an “as is” and “as available” basis.

E Windowtastic does not warrant that:

• The website will always be available, secure, or error-free
• Website information will always be complete, current, or accurate
• Defects or errors will be corrected immediately
• The website will be free from viruses or other harmful components
• Products shown on the website will be available for every location or project
• Use of the website will produce a particular business or project outcome

Product or service warranties, if any, are provided only through the applicable written order, contract, manufacturer warranty, or other project-specific documentation.

Nothing in these Terms excludes a warranty or right that cannot legally be excluded.

15. Limitation of Liability

To the fullest extent permitted by law, E Windowtastic and its owners, employees, representatives, contractors, suppliers, and affiliates will not be liable for indirect, incidental, special, consequential, exemplary, or punitive damages arising from your use of—or inability to use—the website.

This includes loss of profits, business opportunities, data, goodwill, or anticipated savings.

To the extent permitted by law, E Windowtastic’s total liability for a claim arising solely from your use of the website will not exceed $100.

These limitations do not apply where liability cannot be limited or excluded under applicable law. Liability related to a specific purchase or project may be governed by the applicable written agreement.

16. Indemnification

To the extent permitted by law, you agree to defend, indemnify, and hold harmless E Windowtastic and its owners, employees, representatives, contractors, and affiliates from claims, liabilities, damages, losses, and reasonable expenses arising from:

• Your misuse of the website
• Your violation of these Terms
• Information or materials you submit
• Your infringement of another party’s rights
• Your violation of applicable law

17. Changes to the Website and These Terms

We may modify, suspend, or discontinue any part of the website without notice.

We may also update these Terms of Use periodically. Updated Terms will be posted on this page with a revised “Last Updated” date.

Your continued use of the website after updated Terms are posted means you accept the revised Terms.

18. Governing Law

These Terms are governed by the laws of the State of Colorado, without regard to conflict-of-law principles.

Any dispute arising from these Terms or use of the website will be brought in a court of competent jurisdiction located in Colorado, unless applicable law requires otherwise.

19. Severability

If any provision of these Terms is determined to be invalid or unenforceable, the remaining provisions will continue in full force. The invalid provision will be modified only to the extent necessary to make it enforceable.

20. No Waiver

If E Windowtastic does not enforce a provision of these Terms, that does not waive its right to enforce the provision later.

21. Entire Agreement

These Terms and the Privacy Policy constitute the entire agreement concerning your use of the website.

Separate quotations, orders, invoices, contracts, warranties, or project agreements may contain additional terms governing particular products and services.

22. Contact Us

If you have questions about these Terms of Use, contact:

Egress Windowtastic / E Windowtastic
Denver, Colorado, United States
Email: axel@ewindowtastic.com
Website: https://www.ewindowtastic.com/